Full Text
O.M.P. 243/2009
BHARAT SANCHAR NIGAM LIMITED (BSNL) ..... Petitioner
Through: Mr. Sanjeev Narula, Advocate.
Through: Mr. Dhanesh Relan, Advocate.
Date of Decision: FEBRUARY 24, 2010
JUDGMENT
1. Whether the Reporters of local papers may be allowed to see the judgment? Yes.
2. To be referred to the Reporter or not? Yes.
3. Whether the judgment should be reported in the Digest? Yes.
JUDGMENT
MANMOHAN, J (ORAL)
1. Present objection petition has been filed under Section 34 of the Arbitration and Conciliation Act, 1996 (hereinafter referred to as the “Act, 1996”) for setting aside the arbitral award dated 16th February, 2009 passed by the sole Arbitrator Shri Prem Kumar in Arbitration Case No.40/2006.
2. The relevant facts of this case are that on 12th June, 1998 2010:DHC:1125 Jelly filled (PIJF) telephone cables. Section III of Notice Inviting Tender (hereinafter referred to as “NIT”) contains the General (Commercial) Conditions of Contract. Clauses 6 and 13 whereof stipulate with regard to delivery of goods and changes in purchase order as under: “6. DELIVERY AND DOCUMENTS: xxx xxx xxx 6.[2] The delivery of the goods and documents shall commence within 4 weeks of placement of purchase order on vendor and shall be completed as stipulated in the P.O. 6.[3] Supply shall be completed within a period of 2-6 months from the date of issue of Advance purchaser order.
13.
CHANGES IN PURCHASE ORDER 13.[1] The purchaser may, at any time, by a written order given to the supplier, make supplies within the general scope of the contract in any one or more of the following:a) Drawings, designs or specifications, where goods to be furnished under the contract are to be specifically manufactured for the purchaser; b) The method of transportation or packing; c) The place of delivery; or d) The services to be provided by the supplier. 13.[2] If any such changes causes an increase or decrease in the cost of, or the time required for the execution of the contract an equitable adjustment shall be made in the contract price shall accordingly be amended. Any proposal by the supplier for adjustment under this clause must be made within thirty days from the date of the receipt of the change in order.” (emphasis supplied)
3. Section II of NIT contains instructions to bidders. Clause 27 whereof states with regard to advance purchase order and purchase order as under:- “27.
ISSUE OF ADVANCE PURCHASE ORDER: 27.[1] The issue of a first advance purchaser order shall constitute the intention of the purchaser to enter into the contract with the bidder. Purchase orders will be the issued contract with the bidder. Purchase orders will be issued over the period of one year from the date of the issue of first advance purchase order for the requirement of the purchaser. 27.[2] The bidder shall within 20 days of issue of the advance purchase order, give his acceptance along with performance security in conformity with Section IX provided with the bid documents.”
4. On 31st July, 1998 the tender was opened and respondentclaimant’s bid was accepted by the petitioner-objector.
5. On 09th October, 1998 an advance purchase order was issued by the petitioner-objector. The delivery schedule stipulated in the advance purchase order read as under:- “4.[2] The supplies are to be completed maximum within six months from the date of issue of purchase order by the Telecom Circle(s)/District(s). However, the ordered the said period of supply. However, subject to mutual consultation between the circle and vendor, the monthly schedule can be determined keeping in view the circle requirement and incorporated in the APO. Any slippage in the supply as per the monthly delivery schedule shall attract Liquidated Damage Charges as per clause 16 of Section III of the Bid document. The pro rata delivery per month will reflect in the delivery rating of the P.O. of the Vendor.”
6. On 30th October, 1998, petitioner-objector issued the final purchase order wherein it was stipulated that supplies shall be completed within six months from the date of issue of purchase order. Clauses 22 and 25 of the said purchase order read as under:- “22. Delivery Schedule:The supplies are to be completed maximum within six months from the date of issue of purchase order. The sizewise ordered quantity shall be evenly distributed for each month over the said period of supply.
25. Other commercial/legal terms and conditions not covered here shall be governed by the provisions contained in the Tender documents No. T/E MM/SW/016998/000142 opened on 31-7-98 and APO No 203/2/98-MMS dated 09-10-98.”
7. Since the respondent-claimant could not supply the cables till 30th April, 1999, petitioner-objector extended the delivery schedule till 22nd May, 1999. The petitioner-objector’s letter dated 04th May, 1999 extending the delivery schedule on the condition that liquidated damages would be payable in accordance with purchase order dated 30th October, 1998, reads as under: “DEPARTMENT OF TELECOM O/o Chief General Manager H.P. Telecom Circle Shimla 171006 Memo No: Engg/MM-38/Cables/98-99/158 Dated: 04-05-09 In accordance with this office letter of even No dated 23-04-99, approval of Chief General Manager Telecom H.P. Circle is hereby accorded for extension in Delivery Schedule till 22-05-99 with imposition of Liquidated Damages Charges as applicable for supply of balance quantity of cables ordered vide this office Purchase No dated 30-10-1998. The rates applicable for cable supplied during extended period shall be @ 90% provisionally subject to finalization by DOT. Other terms and conditions remain unchanged. Sd/- Sandeep Diwan DGM(Dev) Cc to:
1. PARAMOUNT COMMUNICATIONS LIMITED M-4, Bahubali 59/17, New Rohtak Road C, New Delhi-110005.
2. DDG(MM-II) Department of Telecom, Sanchar Bhawan, New Delhi.
3. CGM(QA) 61, Cock Burn Road, Bangalore 4. 4-6. DET (QA) New Delhi/Gurgaon/Chandigarh.
7. CAO o/o CGMT HP Circle Shimla. 8-9. GM TD Shimla/Dharamsala. 10-13. TDM Solan/Mandi/Hamirpur/Kullu.”
8. Respondent-claimant had no objection to levy of liquidated damages for delay in supply from 30th April, 1999 till the date of unilaterally amended the advance purchase order as well as the purchase order by stipulating that the supplies shall be completed within a period of two to six months from the date of issue of advance purchase order. It was further stated in the said letter that liquidated damages for delay in supplies would be payable in accordance with Clause 16 of Section III of the NIT. The letter dated 10th April, 2000 reads as under: “DEPARTMENT OF TELECOM SERVICES OFFICE OF THE CHIEF GENERAL MANAGER TELECOM H.P. CIRCLE, SHIMLA-171009 To M/s. Paramount Communication Limited, M-4, Bahubali, 59/17, New Rohtak Road, New Delhi-110005. No: Engg/MM-38/Cables/98-99/181 Dated 10-4- Sub: P.O. No.Engg/MM-38/Cables/98-99/74 Dated 30- 10-98- Amendment thereof. In pursuance of DOT letter No. 203-9/96-MMS/927 dated 31-8-99 and letter No. 203-9/96-MMS/1371 dated 29-12-99, the following amendments in respect of relevant clauses of above cited Purchase Order is hereby issued.
1. As per clause 6.[3] of Section-III of the governing Bid document T/E No. MM/SW/061998/000142 opened on 31-8-98. “supply shall be completed within a period of 2-6 months from the date of issue of the Advance Purchase Order.” Therefore the delivery schedule clause No.4.[1] of the APO stand deleted and clause No.4.[2] shall stand partially modified to be in line with above stated bid provisions. As the delivery period has to be counted from 9-10-98, the maximum permissible delivery schedule would end on 8-4-
99. The supplies received on or after 9-4-99 would mean supplies received during extended
2. The prices shall be applicable as conveyed vide DOT letter No.203-9/96-MMS/927 dated 31-8-99.
3. Liquidated damages for delayed supplies will be applicable in accordance with the provisions in the clause 16 of Section-III of the above cited Bid document. All the relevant clauses of the P.O. may be treated as amended to this extent. This issues with the concurrence of IFA. Sd/- (Harbhajan Singh) Asstt. General Manager(MM) Copy forwarded for information and necessary action to:
1. DDG(MM-II),DOT, New Delhi.
2. ADG(ST), DOT, New Delhi.
3. CGM(QA), 61-Cock Burn Road, Bangalore-51.
4. DET(QA), New Delhi.
5. CAO o/o CGMT HP Circle, Shimla. Sd/- Asstt. General Manager(MM)”
9. On 13th April, 2000, petitioner-objector issued a letter to respondent-claimant whereby the delivery schedule was re-fixed from 30th April, 1999 to 09th April, 1999 and amount of Rs.12,11,839/- was alleged to be payable by the respondent-claimant on account of liquidated damages. The relevant portion of the letter dated 13th April, 2000 reads as under: “Dear Sir, In pursuance of order contained in DOT letter No. schedule/monthly delivery schedule has been re-fixed in respect of PO No. Engg/MM-38/Cables/98-99/74 dated 30.10.98 (APO No. 203-2/98-MMS dated 09.10.1998) placed on M/s. Paramount Communication Ltd., vide this office OM. No. Engg./MM-38/Cables/98-99/181, dated 10.04.2000. Accordingly invoice values and LD charges have been recalculated again as per Annexure attached and the competent authority is hereby conveyed for affecting recovery of Rs. 12,11,839/- (Rs. Twelve lakh eleven thousand, eight hundred thirty nine only). The brief detail is as under please.
┌────────────────────────────────────────────────────────────────┐ │ Sl. Calculation taking Received │ │ D/schedule 6 calculation │ │ months from the taking │ │ date of issue of D/schedule 6 │ │ P.O. as already months from │ │ finalized vide O.M. the date of │ │ No. Acctts/3- issue. │ │ 184/CP/Cables/98- │ │ 99/IV/286 │ │ dt.21.09.99 │ ├────────────────────────────────────────────────────────────────┤ │ 1. Admitted Rs. 11,09,57,236/- 110885390/- │ │ invoice │ │ value of │ │ PO │ │ 2. Less LD Rs.10,34,905/- 2174901/- │ │ charges for │ │ monthly │ │ slippage │ │ 3. Final Rs.10,99,22,331/- 10871049/- │ │ admitted │ │ value of │ │ PO │ │ 4. Less Rs.10,99,22,331/- 10,99,22,331/- │ │ amount │ │ already │ │ paid │ │ 5. Net NIL (-)12,11,839/- │ │ Balance │ │ payable/Re │ │ coverable. │ └────────────────────────────────────────────────────────────────┘
13. Relief I hereby pass award in favour of the claimant and against the respondent for a sum of Rs.21,96,556/along with interest @ 9% per annum on the amount of Rs.12,11,839/- w.e.f. today until realization.”
12. Ms. Sanjeev Narula, learned counsel for petitioner-objector submitted that impugned award was contrary to the contract inasmuch as by virtue of letters dated 10th and 13th April, 2000, petitionerobjector had only brought the advance purchase order and the purchase order in conformity with the provisions of NIT. According to Mr. Narula, by virtue of letters dated 10th and 13th April, 2000, the discrepancy which had crept into the advance purchase order and the purchase order was rectified.
13. On the other hand, Mr. Dhanesh Relan, learned counsel for respondent-claimant submitted that the impugned award was in conformity with the NIT inasmuch as Clause 27 of Section II of the NIT specifically stipulated that purchase order would be the governing contract between the parties. In this connection, he relied upon Clauses 22 and 25 of the purchase order dated 30th October, 1998, which have been reproduced hereinabove.
14. Having heard the parties at length and having perused the impugned Award, I am of the view that it would be appropriate to first outline the circumstances in which a Court can interfere with an arbitral award passed under the Act, 1996. The Supreme Court in Delhi Development Authority Vs. R.S. Sharma and Company, New Delhi reported in (2008) 13 SCC 80 after referring to a catena of judgments including Oil & Natural Gas Corporation Ltd. v. Saw Pipes Ltd. reported in (2003) 5 SCC 705 has held that an arbitral award is open to interference by a court under Section 34(2) of the Act, 1996 if it is contrary to either the substantive provisions of law or the contractual provisions and/or is opposed to public policy.
15. In fact, the Supreme Court in McDermott International Inc. Vs. Burn Standard Co. Ltd. & Ors. reported in (2006) 11 SCC 181 has succinctly summed up the scope of interference by this Court by stating “ the 1996 Act makes provision for the supervisory role of courts, for the review of the arbitral award only to ensure fairness. Intervention of the court is envisaged in few circumstances only, like, in case of fraud or bias by the arbitrators, violation of natural justice, etc…...”
16. Applying the aforesaid parameters, I am of the view that impugned Award calls for no interference as the learned Arbitrator has given cogent reasons for award of the respondent-claimant’s claim.
17. I am also of the opinion that Clause 6.[3] of the General Conditions of Contract was not to be mandatorily incorporated in each and every contract and it was open to petitioner-objector corporation to stipulate a different period of supply in the purchase order. In fact, this would be apparent from Clause 27 of Section II of the NIT itself as it stipulated that the purchase order would be the governing contract between the parties and further that purchase orders could be issued over a period of one year from the date of issue of first advance purchase order. objector corporation to unilaterally amend the delivery schedule in the purchase order retrospectively. This was not only contrary to the contractual terms but also highly inequitable besides being unethical. In fact, the practice to unilaterally amend the terms of a duly executed contract retrospectively is deprecated. Accordingly, I direct the Chairman and Managing Director of petitioner-objector Corporation to issue general practice directions to its officers not to unilaterally amend provisions of the contract retrospectively. With the aforesaid observations, present petition is dismissed but with no orders as to costs. MANMOHAN,J FEBRUARY 24, 2010 js